DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 1 of 57
DeKalb County Board of Education
Operations Division
Sam A. Moss Service Center
1780 Montreal Road
Tucker, GA 30084-6705
Request for Proposals (RFP) No. 25-752-002
for
GENERAL CONTRACTOR SERVICES
Project: SECURITY VESTIBULE (KELLEY LAKE ES, LITHONIA MS AND TUCKER HS)
DCSD Project No.: N/A
Owner: DeKalb County Board of Education (the “Board”)
Solicitation Timeline Summary (Subject to Change)
EVENT DATE(S) TIME LOCATION
Solicitation Opens January 9, 2025 http://dekalbschoolsga.ionwave.net
Virtual Mandatory Pre-
January 23, 2025 11:00 AM Via TEAMS
Proposal Conference
Mandatory Site Visit January 27, 2025 9:00 AM Various Location
Final Questions Due January 29, 2025 2:00 PM dcsd-op-bidquestion@dekalbschoolsga.org
Final Addendum February 5, 2025 2:00 PM http://dekalbschoolsga.ionwave.net
Proposal Due Date & Time February 13, 2025 2:00 PM http://dekalbschoolsga.ionwave.net
Public Acknowledgement 5:00 PM http://dekalbschoolsga.ionwave.net
February 17, 2025
Selection Committee
February 18-21, 2025
Evaluation
Anticipated Board Review
April 21, 2025
and Approval
Anticipated Notice of Award April 21, 2025
Anticipated Notice to
May 2025
Proceed
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 2 of 57
TABLE OF CONTENTS
I. ADVERTISEMENT FOR SEALED PROPOSALS GENERAL CONTRACTOR ............................................ 3
II. DEFINITIONS .............................................................................................................................................. 4
III. GENERAL CONDITIONS ........................................................................................................................... 5
IV. INSTRUCTIONS TO PROPOSERS........................................................................................................... 9
V. INSTRUCTIONS FOR SUBMITTING PROPOSALS ................................................................................ 18
VI. QUALIFICATIONS FOR SELECTION AND THE SELECTION PROCESS ............................................. 25
VII. PROTEST PROCESS............................................................................................................................. 26
Owner’s Standard Forms (included with RFP):
Attachment A General Contractor Checklist and Certification (2 pages)
Attachment B1 Corporate Certificate (1 page)
Attachment B2 Partnership Certificate (1 page)
Attachment B3 Entity Certificate (1 page)
Attachment C1 Subcontractor Listing Kelley Lake ES (1 page)
Attachment C2 Subcontractor Listing Lithonia MS (1 page)
Attachment C3 Subcontractor Listing Tucker HS (1 page)
Attachment D Offeror’s and Individuals’ Affidavit of Non-collusion (2 pages)
Attachment E Conflict of Interest Disclosure Form (2 pages)
Attachment F Consent to Release Information (1 page)
Attachment G Vendor Reference Form (1 page)
Attachment H Bid Bond (1 page)
Attachment I1 Fixed Price for Construction Proposal Kelley Lake ES (4 pages)
Attachment I2 Fixed Price for Construction Proposal Lithonia MS (4 pages)
Attachment I3 Fixed Price for Construction Proposal Tucker HS (4 pages)
Attachment J Immigration and Security Certification (2 pages)
Attachment K No Submittal Response Form (1 page)
Owner’s Project Specific Information (separate file from RFP)
Appendix A Owner’s Criteria and Narrative Scope of Work (2 pages)
Appendix B Special Conditions (5 pages)
Appendix C Master Project Schedule (1 page)
Appendix D DeKalb County School District 2024-2025 and 2025-2026 Calendars (2 pages)
Appendix E1 Fixed Price Construction Contract Kelley Lake ES (45 pages)
Appendix E2 Fixed Price Construction Contract Lithonia MS 45 pages)
Appendix E3 Fixed Price Construction Contract Tucker HS (45 pages)
Appendix F Subcontractor Affidavit of Non-collusion (1 page)
Appendix G Performance Bond (3 pages)
Appendix H Payment Bond (4 pages)
Appendix I Affidavit for Payment (2 pages)
Plans and Specifications
Available by request: 100% Construction Documents prepared Croft and Associates dated 02/23/2024
angela_arlene-myrick@dekalbschoolsga.org
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 3 of 57
I.
ADVERTISEMENT FOR SEALED PROPOSALS
GENERAL CONTRACTOR
Proposals will be received electronically on the DeKalb County School District (“Owner”) website at
https://dekalbschoolsga.ionwave.net until 2:00 p.m. local time on Thursday, February 13, 2025, for General
Contractor services for RFP No. 25-752-002, Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS).
The Owner shall not consider late proposals.
Scope of Services
To provide General Contractor services for the construction (Site, Bldg. and Systems) of the Owner’s Construction
Project at Kelley Lake Elementary School, Lithonia Middle School and Tucker High School as specified per the
Proposal Documents.
Request for Proposal (“RFP”) documents will be available Thursday, January 9, 2025, may be obtained from the
DeKalb County Board of Education website at https://dekalbschoolsga.ionwave.net. Plans and Specifications are
available electronically in PDF format and can be emailed to prospective Respondents free of charge by submitting a
request to angela_arlene-myrick@dekalbschoolsga.org.
VRTUAL MANDATORY PRE-PROPOSAL CONFERENCE
A virtual mandatory Pre-Proposal Conference will be held via TEAMS at 11:00 a.m. local time on Thursday, January
23, 2025. Prospective bidders must provide the following information by 5:00 PM, EST on Wednesday, January 22,
2025:
1. Individual Name and Title
2. Company Name
3. Telephone Number
4. Email Address
This information must be sent to dcsd-op-solicitation@dekalbschoolsga.org. A meeting link will be sent to all those
providing the above information no later than 9:30 AM EST on Thursday, January 23, 2025.
There will be mandatory site visits starting at 9:00 AM EST on Monday, January 27, 2025. Attendance is
mandatory.
Schedule for Selection (dates are subject to change)
Virtual Mandatory Pre-Proposal Conference* January 23, 2025 @11:00 am
Mandatory Site Visit January 27, 2025 9:00 am
Final Questions Due January 29, 2025 not later than 2:00 pm
Final Addendum Issued (if necessary) February 5, 2025 not later than 2:00 pm
Proposals Due February 13, 2025 not later than 2:00 pm
Public Acknowledgement February 17, 2025 not later than 5:00 pm
Anticipated Board Review and Approval April 14, 2025
*OPEN TO PUBLIC ATTENDANCE*
The meeting will be held via TEAMS. Please refer to “Virtual Mandatory Pre-Proposal Conference” for instructions to
receive meeting link.
Except as expressly provided in, or permitted by, the Proposal Documents, from the date of issuance of the
RFP until final Owner action of approval of contract award, the Contractor submitting a Proposal shall not
initiate any communication or discussion concerning the Project, the RFP or the Contractor’s Proposal or any
part thereof with any employee, agent, or representative of the Owner. Any violation of this restriction may
result in the rejection of the Contractor’s Proposal.
The Owner reserves the right to reject any or all proposals, and to waive technicalities and informalities.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 4 of 57
II.
DEFINITIONS
A. Proposal Documents means the Advertisement for Proposals, the Instructions to Proposers, the Bid Form,
the form of Bid Bond, the form of Subcontractor Listing, the form of Corporate Certificate, the form of
Partnership Certificate, the form of Entity Certificate, the form of Offer’s and Individuals’ Affidavit of Non-
collusion, the Form of Fixed Price Construction Contract (with exhibits), the form of Performance Bond, the
form of Payment Bond, the Wage Rate Determination (if applicable), the Special Conditions, the Plans and
Specifications, all other proposed contract documents, and any Addenda issued prior to Bid opening.
B. Definitions contained in the proposed contract documents shall be applicable to the Proposal Documents.
C. Addenda are written or graphic instruments issued by the Architect prior to Proposal opening which modify or
interpret the Bidding Documents by additions, deletions, clarifications, corrections or revisions.
D. A Proposal is a complete and properly executed proposal to do the Work in accordance with the Contract for
the sums stipulated in the Proposal supported by data required by the Proposal Documents, submitted in
accordance with the Proposal Documents.
E. The Base Bid is the sum stated in the Bid for which the Bidder offers to perform the Work described in the
Proposal Documents as the base to which Work may be added, or from which Work may be deleted, for sums
stated in the Alternates, if any.
F. An Alternate Bid is an amount stated in the Bid to be added to, or deducted from, the amount of the Base Bid
if the corresponding change in the Work, as described in the Proposal Documents (“Alternate”), is accepted.
G. A Unit Price is an amount stated in the Bid as a price per unit of measurement for specified materials,
equipment or services or a portion of the Work as described in the Bidding Documents.
H. A Proposer is a person or entity who submits a Proposal.
I. A Sub-bidder is a person or entity who submits a bid to a Bidder for materials, equipment or labor for a portion
of the Work.
J. The Owner for whom the work will be executed is the DeKalb County Board of Education, 1701 Mountain
Industrial Boulevard, Stone Mountain, GA 30083.
K. The Owner has selected as Architect the Architect listed in the Advertisement for Proposals, who has prepared
plans and specifications and who will administer the Contract for construction. If the Owner’s design
professional for the Project is an engineer rather than an architect, then the term “Architect” as used
throughout these Instructions to Proposers shall mean “Engineer”.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 5 of 57
III.
GENERAL CONDITIONS
A. Respondent Performance
The successful Respondent is required to perform and fulfill all the undertakings, covenants, terms, conditions,
and agreements of this RFP document and any negotiated contract(s). Failure of the Respondent to fully
perform these obligations may result in cancellation of the award and contract.
DCSD will look to the Respondent and his/her identified personnel to coordinate and deliver the services
described in this RFP. The obligations of the contract shall not be delegated to subcontractors or assigned to
any third party.
B. Non-Discrimination
DCSD does not discriminate on the basis of race, color, religion, sex, national origin, age, or disability in any
of its employment practices, education programs, services or activities.
DCSD supports an open, fair, and impartial free-market system which maximizes competition and seeks to
include all responsible businesses and to provide ample opportunities for business growth and development.
Minority businesses are encouraged and given the opportunity to bid on various projects; however, all
responses will be evaluated on the same criteria. It is not the intention or desire of DCSD to restrict or impede
competition, nor to increase the cost of the work.
C. Drug-Free Workplace
By submission of a response to this RFP, the Respondent certifies that he/she and his/her employees shall
not engage in the unlawful manufacture, sale, distribution, dispensation, possession, or use of controlled
substance or drugs during the performance of the contract.
D. Smoke-Free Workplace
By submission of a response to this RFP, the Respondent certifies that he/she and his/her employees shall
not use tobacco products on DCSD property at any time during the performance of this contract.
E. Costs Incurred
DCSD is not liable for any costs incurred by a Respondent in preparing and/or submitting a response to this
RFP or for any interview if requested. Any and all costs incurred by the Respondent in preparing and/or
submitting a response to this RFP and interviewing with DCSD (if requested) shall be the sole responsibility
of the Respondent and shall not be reimbursed by DCSD.
F. Insurance
A Certificate of Insurance and/or ACORD form is required with solicitation submittal. Provision of
Certificate of Insurance is a mandatory requirement (include with Required Forms). Proposals submitted with
certificates of insurance will be considered conditionally responsive to the insurance and indemnification
requirement. Final award of this RFP will be contingent upon receipt within five (5) business days of request
for insurance documentation complete with the following requirements. In the event the awarded Respondent
cannot produce insurance coverage acceptable to the DCSD within the time provided, DCSD reserves the
right to award this solicitation to the next highest ranked firm. Please refer to Exhibit “D” of the Contract for
required Insurance.
G. Indemnification
The Contractor shall indemnify and hold the Owner harmless from any and all claims, liability, damages, loss,
liens, costs and expenses of every type whatsoever including, without limitation, attorneys' fees and expenses,
arising out of or in connection with the Contractor's performance of this Contract and the Work, to the extent
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 6 of 57
caused by the Contractor, or anyone for whose acts the Contractor is or may be responsible or liable,
regardless of whether such liability, claim, damage, loss, cost or expense is caused in part by the Owner. The
Contractor shall not indemnify or hold harmless the Owner against claims for damages, losses, or expenses,
including attorneys’ fees, caused by or resulting from the sole negligence of the Owner, or its officers, agents
or employees; provided, however, this indemnification obligation shall not be limited by any limitation on
amount or type of damages, compensation, or benefits payable by or for the Contractor or its subcontractors,
sub-subcontractors, or suppliers under workers’ compensation acts, disability benefit acts or other employee
benefit acts.
H. Interviews
DCSD reserves the right to require Respondents to participate in one or more interviews with DCSD staff.
Respondents must be prepared to discuss the salient points of their proposal within three (3) normal working
days of being asked to participate in interviews. There are to be no presentations, individually or collectively,
without such an invitation.
I. Contract Terms
Appendix E is DeKalb County School District’s Standard Form of Contract for Fixed Price Construction
Services between the DeKalb County Board of Education and the General Contractor; Version 05.2022, which
specifically outlines the contractual responsibilities. All responders should thoroughly review the
documents prior to submitting a proposal. Any proposed revisions to the terms or language of these
documents must be submitted in writing during the question and answer period of the solicitation.
All request must be submitted in writing prior to the close of the final questions. Request for revisions
will be reviewed and approved or rejected by legal and legal rulings are final. If submitted or proposed
thereafter, such proposed revisions to the terms or language of these documents shall not be considered by
the Owner and the Service Contractor’s Proposal shall be rejected. No alterations can be made to the contract
after award by the DeKalb County School District.
J. Permits and Applicable Law
Respondents shall at their own expense obtain all necessary permits, certifications, and licenses and shall
comply with all applicable local, state, and federal laws, ordinances, rules, and regulations necessary to fully
execute the requirements stated herein. Respondents shall maintain all such permits, licenses, certifications,
and compliances in a current status throughout the course of the contract. Respondents shall submit copies
of permits, licenses, and certifications evidencing proof of the aforementioned immediately upon request of
DCSD. Respondents shall be in compliance with registration with the Georgia Secretary of State’s office as
applicable.
K. Non-Collusion
Respondents shall fully certify that they, as individuals or as officials of a business entity, have not entered
into any agreement, participated in collusion, or otherwise taken any action in restraint of free and competitive
responses to this RFP. Further, Respondents guarantee that their response is not made in conjunction with
or on behalf of another party and that they have not been directly or indirectly induced in any manner or taken
any action to result in a restriction of trade or in an unfair advantage.
L. Conflict of Interest
Respondents shall disclose with their proposal the name of any officer, director, or agent who also is a DCSD
employee or DeKalb County Board of Education member. Respondents shall also disclose the name of any
DCSD employee or board member who owns, directly or indirectly, an interest in five percent or more in the
Respondent’s company or any of its branches. Respondents shall certify that their response to this RFP is
impartial, at arms-length, and free of any conflict of interest, unfair advantage, or personal benefit to any
DCSD official.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 7 of 57
M. Confidentiality and Non-Disclosure
Information made available to Respondents by DCSD shall be used only for purposes related to responding
to this RFP and shall not be used for any other purpose without the express written permission of DCSD.
Respondents to this RFP unequivocally agree to assume responsibility for protecting and safeguarding the
confidentiality of DCSD records that are not public information. Such information may include but is not limited
to student and human resource file contents.
N. Business License
Respondents shall submit with their proposal, a copy of their valid company business license. If the
Respondent is a Georgia corporation, Respondent shall submit a valid county or city business license. If the
Respondent is not a Georgia corporation, Respondent shall submit a certificate of authority to transact
business in the state of Georgia and a copy of their valid business license issued by their home jurisdiction.
If Respondent holds a professional certification which is licensed by the state of Georgia, Respondent shall
submit a copy of their valid professional license. Any license submitted in response to this requirement shall
be maintained by the Respondent for the duration of the contract. Provision of copy of a business license and
General Contractor license is a mandatory requirement (include with Required Forms).
O. Rights Reserved
DCSD reserves the right to accept or reject any and/or all parts of responsive proposals received and/or to
reject all proposals submitted. DCSD reserves the right to award any resulting contract in the manner that is
in the best interest of and most advantageous to DCSD. DCSD reserves the right to waive any technicalities
or minor irregularities in responses received and to award the contract in the most beneficial manner for
DCSD. The decision of DCSD shall be final.
DCSD reserves the right to request and negotiate a “best and final” response from Respondents.
P. Taxes
Purchases made by DCSD are not subject to federal, state, or local sales tax. A Sales Tax Exemption
Certificate will be furnished upon request.
Q. Conditional Proposals
Proposals that are conditional and/or in any way qualify or vary the terms of these instructions, conditions,
and specifications shall be considered non-responsive and disqualified.
R. Respondent Failure
In the event services to be furnished by the successful Respondent should for any reason fail to conform to
the scope of work contained herein, DCSD reserves the right to reject the services and further reserves the
right to terminate the contract.
Failure of the successful Respondent to perform contracted services may also result in the removal of that
Respondent from doing business with DCSD for a period of not less than one year.
S. Georgia Open Records Act
Without regard to any designation made by the person or entity making a submission, DeKalb County School
District considers all information submitted in response to this invitation or request to be a public record that
may be disclosed upon request pursuant to the Georgia Open Records Act, O.C.G.A. 50-18-70 et seq., without
consulting or contracting the person or entity making the submission, unless a court order is presented with
the submission. You may wish to consult an attorney or obtain legal advice prior to making a submission.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 8 of 57
T. No Assignment of Award
The successful Respondent may not assign the award or contract to or subcontract with another party
without the express written permission of DCSD.
U. The Laws of the State of Georgia
This RFP and subsequent agreements are subject to the laws of the State of Georgia.
V. Proposal Duration
Proposals submitted in response to this RFP must be valid for a period of ninety (90) days from proposal
submission deadline, as indicated by submission of the Fixed Price Proposal Fee Form.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 9 of 57
IV.
INSTRUCTIONS TO PROPOSERS
1. INTRODUCTORY:
To be considered, Proposals must be made in accordance with the following instructions and must be
received electronically on the DeKalb County School District website at https://dekalbschoolsga.ionwave.net
not later than the date and time set forth in the "Advertisement for Sealed Proposals – General Contractor”
or any extension thereof made by Addendum.
The Owner reserves the right to reject any or all Proposals and to waive any technicalities and
informalities.
2. OWNER:
The Owner for whom the GC Services and the Work will be executed is:
DeKalb County Board of Education
1701 Mountain Industrial Boulevard
Stone Mountain, Georgia 30083
3. ARCHITECT:
The Architect is:
Croft and Associates
3380 Blue Springs Road
Kennesaw, GA 30144
4. VIRTUAL MANDATORY PRE-PROPOSAL CONFERENCE & SITE VISIT
A virtual mandatory Pre-Proposal Conference will be held via TEAMS at 11:00 a.m. local time on Thursday,
January 23, 2025, Prospective bidders must provide the following information by 5:00 PM, EST on
Wednesday, 22, 2025:
Individual Name and Title
Company Name
Telephone Number
Email Address
This information must be sent to dcsd-op-solicitation@dekalbschoolsga.org. A meeting link will be sent to all
those providing the above information no later than 9:30 AM, EST on Thursday, January 23, 2025.
There will be a mandatory site visit at 9:00 AM EST on Monday, January 27, 2025.
Attendance is mandatory.
5. PROPOSALS:
Proposals are to be submitted electronically at http://www.dekalbschoolsga.ionwave.net.
The following steps must be completed to successfully submit a proposal electronically:
• Respondents are required to register using the IONWAVE portal and obtain a username and
password.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 10 of 57
• Respondents will be required to upload all required documents identified under the Response
Attachments tab.
• After uploading all required documents, Respondents will need to click "Submit Response" under
the Response Submission tab.
• Once all of the required documents have been successfully uploaded, “Submitted” in green will
appear next to Response Status.
• Proposal has not been successfully submitted if you see the following message next to Response
Status: NOT SUBMITTED – To complete your response, you must click ‘Submit Response’ in the
Response Submission tab.
The GC is fully responsible for timely submission. Proposals received after the specified time set will not be
considered by the Owner.
6. DOCUMENTS:
Proposal Documents may be obtained by bona fide GC firms from the DeKalb County School District website
at: http://www.dekalbschoolsga.ionwave.net.
Plans and Specifications are available electronically in PDF format and can be emailed to prospective
Respondents free of charge by submitting a request to angela_arlene-myrick@dekalbschoolsga.org.
GC firms shall use complete sets of Proposal Documents in preparing Proposals. The Owner will not be
responsible for errors or misinterpretations resulting from the use of incomplete sets of Proposal Documents.
The GC firms submitting Proposals are responsible for the review of the Proposal Documents, including
without limitation the Owner’s Standard Forms and Preliminary Design Information.
In making copies of the Proposal Documents available, the Owner does so only for the purpose of obtaining
Proposals for the Project and does not confer a license or grant permission for any other use of the Proposal
Documents.
7. RFP ADDENDA:
Addenda, if any, will be posted on the DCSD website and it is the responsibility of all Proposers and
Subcontractors to check the website for issued addenda. Addenda will also be e-mailed to all who are known
by the issuing office to have attended the Pre-Proposal Conference. Copies of Addenda will be made
available for inspection wherever Proposal Documents are on file for that purpose. No Addenda will be issued
later than 72 hours prior to the time for Proposal opening, except for Addenda withdrawing the Request for
Proposals or Addenda which include a postponement of the date through which Proposals may be submitted.
Each GC firm shall ascertain prior to submitting a Proposal that the GC firm has received all Addenda issued,
if any, and the GC firm shall acknowledge their receipt in the Proposal. Failure of a GC firm to receive or
acknowledge any Addendum shall not relieve the GC firm of any obligation under the Proposal. All Addenda
shall become part of the Contract Documents.
8. SCOPE OF WORK:
The purpose of the security vestibule is to provide a physical security barrier between public
access and the reception lobby and educational spaces at the main entrance of the school. The
scope of the project is to enhance the security measures at the school. This will be done by creating
an entry vestibule utilizing a storefront system that complies with UL 752 Class III classifications,
the installation of a transaction window, and the application of an intrusion resistant film to specific
windows along with the integration of electronic devices for access control and communication.
Refer to the construction documents for further details and clarifications.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 11 of 57
Dekalb County School District – Kelley Lake Elementary School
1. Replace existing exterior main entry storefront system with new bullet resistant storefront system.
2. Provide new interior bullet resistant storefront system between existing corridor and New Vestibule.
3. Provide bullet resistant transaction window with deal tray, between Administration Office and New Vestibule.
4. Existing Administration, Principal office, Assistant Principal office and Teacher’s Lounge windows to receive new
intrusion resistant film applied to both sides of glass with frame anchorage system.
5. Rework existing acoustical tiles, as necessary.
Dekalb County School District – Lithonia Middle School
1. Retrofit existing main entry exterior storefront glazing with bullet resistant glazing and bullet resistant steel
reinforcement at existing aluminum frames.
2. Main entry transom to receive new intrusion resistant film.
3. Main entry storefront doors to be replaced with new bullet resistant storefront doors.
4. Provide new bullet resistant interior storefront system between New Vestibule and existing corridor.
5. Replace existing hollow metal window between Administration and new Security Vestibule with bullet resistant
transaction window with deal tray and new storefront windows.
6. Replace existing hollow metal frame and wood door with new bullet resistant storefront door.
7. Existing Bookkeeper & Principal office windows to receive new intrusion resistant film.
8. Rework existing gypsum wallboard header at new storefront system.
Dekalb County School District – Tucker HS
1. Replace existing main entry storefront system with new bullet resistant storefront system. Transom above to
receive insulated glazing with intrusion resistant film.
2. Provide new bullet resistant interior storefront system between New Vestibule and existing lobby. Transom
above to receive ½” clear glazing with intrusion resistant film.
3. Provide new bullet resistant interior storefront system between New Vestibule and existing corridor.
4. Provide new bullet resistant wall with bullet resistant transaction window unit and two bullet resistant storefront
windows.
5. Reception/ Lobby, Conference and Principal Office existing exterior windows to receive new intrusion resistant
film.
6. Rework existing suspended gypsum wallboard and acoustical tile ceilings, as necessary.
9. INTERPRETATIONS:
The GC firm shall carefully study and compare the Proposal Documents with each other, and with other work
being bid or offered concurrently or presently under construction to the extent that it relates to the GC Services
for which the Proposal is submitted, shall examine the site of the Project and the local conditions, and shall
at once report to the Owner any errors, inconsistencies or ambiguities in the Proposal Documents. If a GC
is in doubt as to the meaning of any part of the Proposal Documents, or otherwise has questions or requires
clarification or interpretation of the Proposal Documents, he or she shall request an interpretation from the
Owner. Requests for such interpretations shall be made in writing addressed to Mr. Erick Hofstetter Chief
Operating Officer, Sam A. Moss Service Center, 1780 Montreal Road, Tucker, Georgia 30084, fax 678-676-
1475, not later than six (6) business days prior to the time for receiving Proposals, and failure of the successful
GC to request such interpretation shall not relieve him or her as a GC of the obligation to execute the GC
Services in accordance with a later interpretation by the Owner, without additional charge to the Owner.
Interpretations, corrections and changes of the Proposal Documents will be made by Addendum. No oral
interpretations will be made to GC as to meaning of Proposal Documents. Any purported interpretations,
corrections and changes of the Proposal Document made in any manner other than Addendum will not be
binding, and GC shall not rely upon them. Any communication, or attempted communication, by a GC or its
agents concerning this Request for Proposals by any means or method other than that provided for in this
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 12 of 57
Request for Proposals shall be inappropriate. In the event of such inappropriate communication, or attempted
communication, the Owner shall have the right to reject such offending Offeror’s Proposal.
10. SUBSTITUTIONS
Unless otherwise indicated in the Proposal Documents, the materials, products and equipment described in
the Proposal Documents establish a standard of required function, dimension, appearance and quality to be
met by any proposed substitution.
No substitution will be considered prior to receipt of Proposals unless written request for approval has been
received by the Owner no later than January 29, 2025 by 2:00 PM EST. All substitution requests shall be
sent to dcsd-op-bidquestion@dekalbschoolsga.org. Such requests shall include the name of the specified
product, material or equipment, and the specification section or other reference to the Proposal Documents
as appropriate. The request shall provide a complete description of the proposed substitution including
drawings, performance and test data, and other information necessary for an evaluation. The request for
approval shall explain fully the difference, if any, between the proposed product and the one or more named
in the specifications, including difference in cost. A statement setting forth changes in other materials,
equipment or other portions of the Work including changes in the work of other contracts that incorporation
of the proposed substitution would require shall be included in the request. The burden of proof of the merit
of the proposed substitution is upon the proposer. The Owner’s decision of approval or disapproval of a
proposed substitution shall be final.
If the Owner approves a proposed substitution prior to the date for receipt of Proposals, such approval will be
set forth in an Addendum. GC firms shall not rely upon approvals made in any other manner.
No substitutions will be considered after the Contract award unless specifically provided in the Contract
Documents.
11. WITHDRAWAL OF PROPOSALS:
Except as may be otherwise expressly provided by law, a GC’s Proposal cannot be withdrawn after it has
been electronically submitted at http://www.dekalbschoolsga.ionwave.net, for a period of ninety (90) calendar
days after the date fixed for receiving said Proposals, and all Proposals are subject to acceptance by the
Owner during said period, and each Offeror so agrees by submitting a Proposal.
12. BACKGROUND CHECKS:
A criminal background check must be performed on all contractors, consultants, subcontractors, volunteers
and vendors (hereinafter jointly referred to as "Individuals") who provide services on DCSD premises,
supervise services on DCSD premises, or has contact with students. These Individuals shall undergo the
same criminal background check, within the last 365 days, as required by DCSD employees. Such
background checks will be performed by DCSD at the expense of the Individual at a cost of $45.00 per
individual. Additionally, any charges against the Individual may be deemed unacceptable in DCSD’s sole
discretion regardless of whether dismissed, expunged, sealed, removed from the record, treated as a “first
offender” or dead docketed. Upon receipt and evaluation of DCSD’s background check results, DCSD may
demand that the Individual have no contact with DCSD students, parents, or provide services to DCSD
premises. Any failure of the contractor to obtain a criminal records background check through DCSD, as
stated herein, may result in termination of any resulting contract between contractor and DCSD
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 13 of 57
13. IRREGULARITIES:
The Owner, at its sole option, may accept or reject Proposals that contain irregularities of any kind, or
Proposals that do not comply fully with the Proposal Documents.
14. CONTRACT AWARD:
Subject to the Owner’s right to reject any or all Proposals, it is the intent of the Owner to award a contract, at
the sole option of the Owner, in due course and after a reasonable Proposal evaluation period, on a fixed
price basis and within the funds available, to the responsible and responsive GC whose Proposal is
determined to be the most advantageous to the Owner, provided that the Proposal otherwise fulfills the
requirements of the Proposal Documents. The Owner shall have the right to waive informalities or
irregularities in a Proposal received and to accept the Proposal that, in the Owner’s judgment, is in
the Owner’s best interest. Proposals will be evaluated on a combination of factors. These factors, and their
relative importance, are:
1. Proposed Project Staff 15 Points
Resumes of key staff assigned to Project 10
Location of Office 2
Organizational Chart as it relates to Project 3
2. Project Approach 20 Points
Knowledge of working on active 5
campuses/codes/ordinances
Approach 5
Schedule 5
QA/QC 5
3. Successful Building Experience 15 Points
4. Current Workload 15 Points
5. Proposed Fixed Price 35 Points
100 Points
*Equitable Distribution 15 Points(maximum)
NOTE: All information identified above in items #1 – 5 is required for this Proposal to be considered.
*The chart included in Section V. Instructions for Submitting Proposals will be used to award a
maximum of 15 points based on dollar amount of projects currently under contract, as well as those awarded
by DCSD, but not yet under contract and those recommended but not yet awarded. This single score will be
allocated to each firm by the Selection Process Facilitator and added to the cumulative score of the committee
members.
Upon approval of the General Contractor (GC) by the DeKalb County Board of Education, the District will issue
a Notice of Award (NOA) in writing, to the GC. The selected GC shall submit all required documentation,
payment and performance bonds on the exact forms provided by the Owner in the RFP, insurance
certifications, executed contract, etc. within five (5) days of NOA issuance. The GC shall submit the Builder’s
Risk policy required by the RFP and contract. The Contractual Schedule included in the RFP and in the
contract will be reduced by any days that exceed the total of five (5) business days identified in Section 12.0.
Notice to Proceed (NTP) with the final executed contract and a revised schedule, if appropriate, shall be issued
to the GC upon receipt of all documents.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 14 of 57
After evaluation of the Proposals received in response to the RFP, DeKalb County School District may
interview two or more proposers deemed fully qualified, responsive, responsible and suitable on the basis of
initial responses, and with professional competence to provide the required services. DCSD is under no
obligation to perform interviews for this RFP.
At the conclusion of the interviews, if they are held, and on the basis of evaluation factors set forth in Section
III and the information provided and developed in the selection process to this point, DeKalb County School
District Selection Committee shall rank, in the order of preference and begin negotiations with the firm whose
proposal is determined to be most advantageous to the Owner. If a contract satisfactory and advantageous
to DeKalb County School District cannot be negotiated, then the Owner reserves the right to automatically,
without notification, terminate such negotiations and enter into negotiations with the second most qualified
firm. Failing accord with the second most qualified firm, DCSD shall terminate negotiations and enter into
negotiations with the third most qualified firm. Should DCSD be unable to negotiate a contract at a fair and
reasonable price with any of the top three selected firms, the selection committee shall select additional firms
in order of their rankings, and DCSD shall continue negotiations until an agreement is reached.
15. GC’S QUALIFICATIONS:
The Owner, before Contract award, will require GC to document that they are “responsible” to the satisfaction
of the Owner. They will thus be required to show that they have the necessary facilities, technical ability,
licenses, and financial resources to execute the Services and the Work in a satisfactory manner, and within
the time specified; that they have had experience in the Services and Work of a similar nature; and that they
have past history and references which will verify their qualifications for executing the Services and the Work.
The Owner shall have the right to make such additional inquiry as it deems necessary to determine the ability
of the GC to perform the Services and the Work in a prompt and efficient matter in accordance with the
Contract Documents. The failure of a GC to promptly supply information in connection with the Owner’s
inquiry shall be grounds for a determination that such GC is not responsive, not responsible, or both. In
determining the qualifications and responsibility of the GC, the Owner may take into consideration any and
all relevant facts and circumstances available to it including, but not limited to, the GC’s experience, capacity,
facilities, previous work standing with DCSD, financial standing, skill, available supervisory personnel,
available labor, current volume of work being performed for DCSD at the time of this procurement process,
quality and efficiency of construction plant and equipment proposed to be utilized on the Project. The Owner
shall have the right to reject the Proposal of any GC failing to show to the satisfaction of the Owner the GC
could perform the Services and the Work in a prompt and efficient manner in accordance with the Contract
Documents. GCs may be afforded an opportunity for discussion, negotiation and revision of Proposals for
the purpose of obtaining best and final offers. In the event the Owner deems it necessary or appropriate,
responsible GCs found by the Owner to have submitted Proposals reasonably susceptible of being selected
for award shall be given an opportunity to participate in such discussions, negotiations and revisions.
The successful GC will also be required to submit appropriate entity and authority certificates acceptable to
Owner as a part of this RFP.
16. OWNER’S CONSTRUCTION MANAGEMENT CONTRACT FORM:
Included and made a part of this RFP is the Owner’s Standard Form of Fixed Price Construction Contract
(the “Agreement” or the “Contract”). GCs are responsible for the review of this document in the preparation
of their Proposals. The successful GC shall comply with all insurance requirements set forth in the Agreement
and any other Contract Documents, and the GC’s attention is directed to the insurance exhibit to the
Agreement. These insurance requirements shall be considered in the preparation of the GC’s Proposal.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 15 of 57
17. COMMENCEMENT, PROSECUTION, AND COMPLETION:
The GC will be required to commence its services under the Owner’s form of Agreement immediately after
its receipt of a written Notice-to-Proceed from the Owner and to prosecute the effort with competence,
faithfulness and energy.
18. BID BOND:
The GC’s Proposal shall be accompanied by a Bid Bond in the exact form set forth herein. The Bid Bond
shall be in an amount not less than 5% of the Fixed Price Proposal. The amount stated in the Bid Bond
shall be included as an exact dollar figure written in numeric and word form. Failure to do so shall
result in your proposal being deemed non-responsive. A Bid Bond submitted using an AIA
document is unacceptable and shall result in your proposal being deemed non-responsive. The
attorney-in-fact who executes the Bid Bond on behalf of the surety shall affix to the Bid Bond a certified and
current power of attorney. The surety must be satisfactory to the Owner, and must be licensed to do business
in Georgia as approved by the State Insurance Commissioner’s Office. No other form of bid security will be
accepted. The Owner shall have the right to retain the Bid Bond of all GCs until either (a) the Agreement has
been executed and a satisfactory Payment Bond and Performance Bond have been furnished, or (b) ninety
(90) days after Proposal opening, or (c) all Proposals have been rejected. Except as otherwise expressly
allowed by law, no Proposal may be withdrawn for a period of ninety (90) days following the closing time and
date for receipt of Proposals, and all Proposals are subject to acceptance by the Owner during said period,
and each GC so agrees by submitting a Proposal.
19. AFFIDAVIT:
As a part of the response to this RFP, the GC shall submit with its proposal an affidavit in the form of the
Offeror’s and Individuals’ Affidavit of Non-collusion included in the Proposal Documents as Attachment D. If
the proposing GC is a partnership, all of the partners and any officer, agent, or other person who intend to
represent or act for them in proposing for or procuring the Contract for the Project shall also sign the affidavit.
If the proposing GC is a corporation or other entity, all officers, agents, or other persons who intend to act for
or represent the corporation or other entity in proposing for or procuring the Contract for the Project shall also
sign the affidavit.
The Subcontractor’s Affidavit of Non-collusion is included with the Proposal Documents as Appendix F. Not
later than simultaneously with the execution of the Contract, the successful Offeror shall deliver to the Owner
the completed and executed Subcontractor’s Affidavit of Non-collusion in accordance with O.C.G.A. § 36-91-
21(e). The GC awarded the contract shall require every Subcontractor from whom the GC received a bid or
proposal to complete and sign the Subcontractor’s Affidavit of Non-collusion.
20. CONFLICT OF INTEREST:
If any officer, director, or agent of the GC is also an employee of the DeKalb County Board of Education, then
the GC shall clearly identify it in your Proposal including the name of the individuals(s) and the position he or
she holds in the organization. Further, the GC shall disclose the name(s) of any DeKalb County Board of
Education employee(s) who owns, directly or indirectly, any interest in your organization or any of its affiliates,
excluding stock in a publicly traded organization if such person owns an interest of ten percent (10%) or less.
The GC shall complete and have notarized a Conflict of Interest Form and include it in the Proposal.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 16 of 57
21. EXISTING CONDITIONS:
The GC is responsible to visit, examine and inspect the site of the proposed Project, obtain first-hand
knowledge of existing conditions, the conformation of the ground, the character, quality and quantity of the
products needed preliminary to and during the prosecution of the Work, the general and local conditions and
all other matters which can in any way affect the Services or the Work to be done under the Agreement, and
become thoroughly familiar with all conditions under which the Work is to be performed and correlate all the
GC’s observations and any other facts or conditions that are known to or reasonably knowable by the GC with
the requirements of the Proposal Documents, including the proposed Contract Documents.
22. SUBSURFACE INVESTIGATIONS:
If soil and subsurface investigations were conducted at the site of the proposed Project, a copy of the report
is included in this RFP as an Appendix. Such information is provided for the purpose of disclosure only, and
shall not relieve the GC from its obligation to investigate the soil and subsurface conditions. The Owner does
not guarantee the accuracy or completeness of the data and shall not be responsible therefore. The GC shall
not rely on such subsurface information and shall make its own investigation of subsurface conditions. The
Owner will not be responsible in any way for additional compensation because of the reliance on or
assumptions based on the soil investigation data furnished with the Proposal Documents.
23. CONSENT TO RELEASE INFORMATION:
By submitting a Proposal, the GC (and in the case of a joint venture, each partner in the joint venture)
authorizes the Owner, and the Owner’s agents, attorneys and other representatives, to contact each and
every reference, person or entity identified in the Proposal. The GC (and in the case of a joint venture, each
partner in the joint venture) agrees that any information concerning the GC (and in the case of a joint venture,
each partner in the joint venture) in possession of any identified reference, person or entity may be fully
disclosed, and made available, to the Owner and its agents, attorneys and other representatives. The
enclosed Consent to Release Information must be executed by the GC (and in the case of a joint venture, by
each partner in the joint venture) and submitted to the Owner with the Proposal.
24. PERFORMANCE AND PAYMENT BONDS:
Performance and Payment Bonds from a surety satisfactory to DCSD must be furnished by the awarded GC
in an amount not less than 100 percent (100%) of the contract price if the contract price is $100,000 or more.
1. Bonding Capacity/Current Workload: The GC must submit a letter from their insurer or surety
stating their (a.) current bonding capacity for a single job and their (b.) aggregate capacity, (c.) current
value of work under contract and (d.) current value of bonded work. Failure to do so shall result in
your proposal being deemed non-responsive.
25. COMMUNICATIONS WITH DCSD STAFF:
It is intended that this proposal be adequate for any vendor to respond to the DeKalb County School District
requirements. However, should proposers have questions, all questions should be submitted electronically
via email to the Procurement Manager at dcsd-op-bidquestion@dekalbschoolsga.org. Questions submitted
to any other email address will not be considered. The deadline for receipt of vendor questions is
Wednesday, January 29, 2025 at 2:00 p.m. Questions received after the deadline time will not be
considered. Questions received by the deadline time will be answered in writing and posted to the website
http://www.dekalbschoolsga.ionwave.net no later than Wednesday, February 5, 2025 at 2:00 p.m.
No response other than written by the Procurement Manager, will be binding upon DCSD.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 17 of 57
The assigned contact persons for this RFP is Angela Arlene-Myrick, Procurement Manager. Mrs. Arlene-
Myrick can be reached at (678) 676-1554 or by email at angela_arlene-myrick@dekalbschoolsga.org.
Prospective Respondents must limit their contact regarding this RFP to the assigned contact persons.
Except with the consent of the proposal contact person, all proposers, including any persons affiliated with or
in any way related to proposers, are strictly prohibited for contacting DeKalb County School District on any
matter having to do in any respect with this RFP, other than as provided herein. Any and all contacts with
such persons associated with DeKalb County School District shall be in writing, in appropriate circumstances
or cases, as directed by the contact person above. Except as expressly provided in, or permitted by, the RFP
documents, for the date of issuance of the Request for Proposals until final DeKalb County Board of Education
action of approval of contract award, the proposer submitting a bid shall not initiate any communication or
discussion concerning this procurement with any employee, agent, representative or member of the Board of
Education for DeKalb County School District. Any violation of this restriction may result in the rejection of the
proposal response.
Except as expressly provided in, or permitted by, the Proposal Documents, from the date of issuance
of the RFP until final Board action of approval of contract award, the Contractor submitting a Proposal
shall not initiate any communication or discussion concerning the Project, the RFP or the Contractor’s
Proposal or any part thereof with any employee, agent, or representative of the Board or Architect.
Any violation of this restriction may result in the rejection of the Contractor’s Proposal.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 18 of 57
V.
INSTRUCTIONS FOR SUBMITTING PROPOSALS
A. SUBMISSION OF PROPOSALS:
Electronic proposals shall be submitted to the website https://dekalbschoolsga.ionwave.net and include
the following:
1) Letter of Introduction - To be included with Technical Proposal under “Response
Attachments”.
2) Table of Contents - To be included with Technical Proposal under “Response
Attachments”.
3) Compliance - To be included with Technical Proposal under “Response Attachments”.
4) Proposed Project Staff - To be included with Technical Proposal under “Response
Attachments”.
5) Project Approach - To be included with Technical Proposal under “Response
Attachments”.
6) Experience - To be included with Technical Proposal under “Response Attachments”.
7) Current Workload - To be included with Technical Proposal under “Response
Attachments”.
8) Fixed Price Proposal - To be uploaded individually under “Response Attachments”.
B. The Offeror’s sealed proposal shall be submitted in the following order and format:
1. Letter of introduction and interest signed by an officer or partner of responding firm. Letter shall
include specific reason(s) why firm would be the best choice for the services listed. Letter shall
include name of entity submitting, contact name, phone number, e-mail address, fax number and
address of firm submitting.
2. Table of Contents
3. Compliance Information
This is a compliance section and carries no evaluation points. Firms must meet minimum
criteria as specified to receive further consideration. Proposals shall include the
following:
3.1 The GC must be properly certified by the Georgia Secretary of State to do business in
Georgia at the time of submission.
3.1.1 State the legal name of entity submitting and if Firm submitting is a corporation,
joint venture, or partnership. Note: It is understood that if selected for this project
the stated entity name will be used in all legal contracting documents derived from
this selection.
3.1.2 Provide a copy of certification for proper incorporation or registration from Georgia
Secretary of State. In the alternative, joint ventures and partnerships should
provide a copy of their joint venture or partnership agreement and certification from
the Georgia Secretary of State establishing that each joint venture partner or
partner is authorized to do business in Georgia.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 19 of 57
3.2 The GC must be properly registered, licensed, and certified at the time of submission:
3.2.1 Provide copy of current Georgia Professional Registration Certificate for general
contractor.
3.2.2 If GC is a joint venture, provide copy of the joint venture agreement and either:
a. Copy of current Georgia Professional Registration Certificate of the
joint venture; or
b. A copy of the current Georgia Professional Registration Certificate of
one of the joint venture partners.
3.3 Financial Information (Y/N):
3.3.1 The Firm’s financial capability is to be expressed in the financial statement
(audited financial information current within the past twelve months, such
as a balance sheet and statement of operations) and should indicate the
resources and the necessary working capital to assure financial stability
through the completion of the projects. A certified audit is preferred;
however, the Firm’s most recent tax return and balance sheet will be
accepted.
3.3.2 Bonding Capacity: The GC must submit a letter from their insurer or surety stating
their current bonding capacity for a single job and their aggregate capacity, current
value of work under contract and current value of bonded work. (The firm will be
required to bond 100% of the cost of the Project).
3.3.3 Compliance Letter: Provide a compliance letter from a bonding company
indicating the bonding company’s A.M. Best financial rating and whether the
bonding company will provide separate Payment and Performance Bonds, each
in the amount of 100% of the Contract Price, on the exact forms provided by the
Owner for your services as GC. Upon award, GC must submit Payment and
Performance Bonds on the exact forms provided by the Owner.
3.4. Litigation/Capacity/Convictions Information (Y/N):
3.4.1 Identify and briefly discuss any instances in the past five (5) years where your
contract was terminated, with or without cause. Provide Owner name, project
name and Owner Project Representative Name and Number. For joint ventures
responding to this RFP, provide the above information as it pertains, to the joint
venture and for each partner or entity creating said joint venture. If there is no
failure or failures to complete a contract, please include a statement that the Firm
has never failed to complete a contract or contracts or have defaulted or have
been declared in default on any contract.
3.4.2 Capacity: Based on your current workforce and staffing in addition to the number
of projects your firm currently has under contract or in negotiation, please
demonstrate your firm’s capacity to complete this project. Describe any claims,
mediation, litigation, arbitration or other form of dispute resolution filed by or
against your company regarding K-12 projects (and, in the case of a joint venture,
by or against any partner in the joint venture) in the past five (5) years, including
case name, number, location of court or arbitration. This list shall also disclose
any failure or failures to complete a contract, or contracts, and any instances of
having defaulted or having been declared to be in default, on any contract(s).
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 20 of 57
3.4.3 Convictions: Include a statement as to whether or not the GC (and in the case of
a joint venture, each of the partners in the joint venture) or any of its officers has
been convicted or entered a guilty plea (or plea of nolo contendere) in any court
within the two (2) years prior to the date of application of a violation of any State
or Federal statute concerning competitive bidding or competitive proposals
or the restraint of trade.
EVALUATION CRITERIA
4. Proposed Project Staff (15 points):
The quality, experience and quantity of staff and their functions will be evaluated by the Committee.
The firm shall name the actual key personnel to be assigned to this Project, describe their ability and
experience, and indicate the function of each within their organization and their proposed role on this
Project. It is the intent that the proposed staff shall be assigned to this Project unless otherwise
approved by Owner. All proposed key staff members must be present at the time of interview unless
prior written approval is received from the Owner.
4.1 Give brief resumes of key personnel (project manager, superintendent, and controls
specialist at a minimum) to be assigned to the Project including, but not limited to, the
following:
a. Name and title.
b. Job assignment for other projects.
c. How many years with this firm? For sub-consultants, list prior projects your firm has
worked with sub-consultant.
d. How many years with other firms?
e. Experience including types of projects, size of projects (dollar value and square
footage of project), and specific project involvement.
f. Education.
g. Active registrations (if any).
4.2 Provide the location of the office(s) that will be providing the required services.
4.3 Organization Chart: Develop an organization chart as it relates to this Project indicating
key personnel and their relationship.
5. Project Approach (20 points):
5.1 The firm shall provide information regarding its knowledge of working on active school
campuses, local codes and ordinances, local subcontractors and suppliers as an indication
of its ability to deliver quality workmanship in an effective and timely manner.
5.2 The firm shall demonstrate verbally and graphically its plan for performing the Project,
documenting the services to be provided and showing the interrelationships of all parties,
including the District’s consultants, departments (IT, FF&E, Transportation, Nutrition, etc.)
local authorities, architects, and Program Manager, to name a few. As part of its services,
the firm shall indicate knowledge and experience in the evaluation of building systems,
construction techniques, and the recommendation of materials to create the optimum value
in meeting the design and budget requirements.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 21 of 57
5.3 Schedule: The Project Master Schedule has been included in this RFP identifying the start
and finish dates for construction. Use the dates shown and develop a Preliminary Schedule
that you plan on using to construct this project.
5.4 QA/QC: Describe your experience and technical expertise your firm will employ with regard
to safety, cost and quality assurance and quality control.
6. Successful Building Experience (15 points)
Please list past experience, including examples of renovations, refurbishments, repairs and new
construction projects completed by the firm. Consideration will be given to the successful completion
of previous projects comparable in design, scope and complexity. This will include evaluating the
firm’s performance and quality of work on previous projects.
List the projects which best illustrate the experience of the firm which utilized the current staff which
is being assigned to this Project. (List no more than 10 projects and do not list projects which were
not completed by your firm or completed more than ten years ago). Include the following for each
project:
a. Name and location of the project.
b. Project owner's representative name, address, telephone and facsimile number.
c. Project user's representative name, address and telephone number.
d. Date project was completed. Provide comparison of original schedule completion to
actual completion date.
e. Size of project (construction gross square feet).
f. Cost of project (construction cost). Provide comparison of original contract amount
with final contract amount
g. Work for which firm and firm's staff was responsible.
h. Firm's project manager, superintendent, and other key professionals involved on the
project and who of that staff would be assigned to the Project covered by this RFP.
7. Current Workload (15 points)
7.1 As part of the evaluation criteria, the Committee will review the firms and their sub-
consultant’s current workload. If the submitting firm is a joint venture, the Committee will
review the current workload of each of the firms comprising the submitting entity.
7.2 Firms and their sub-consultant(s) shall provide a list of projects in construction or closeout,
client names, percent complete on the project, anticipated completion date, and dollars
committed on open project workload. Furthermore, if the submitting firm is a joint venture
they shall also include projects for each firm comprising the joint venture.
7.3 Definition of sub-consultant as it relates to this selection process: An individual and/or firm
contracted or to be contracted by the submitting entity to provide services related to or part
of those which this will be required as part of this selection process.
8. Proposed Fixed Price (35 points) (Use Owner’s “Bid Form” included in this Request for
Proposal.)
8.1 Indicate your proposed Fixed Price for the Services and Work as required by the
Proposal Documents and the Owner’s Agreement. Provide this Fixed Price on the “Bid
Form” attached to this RFP.
a. Indicate any breakdown of the proposed Fixed Price required by the attached “Bid
Form.”
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 22 of 57
b. Indicate any alternates to the proposed Fixed Price required by the attached “Bid
Form.”
c. Acknowledge receipt of addendum, if any.
d. All blanks shall be filled in, and shall be filled in by typewriter or manually and legibly in
ink. Where so indicated on the Owner’s forms, amounts and sums shall be expressed
in both words and numerals, and in case of a discrepancy between the two, the amount
of sum written in words shall govern. Interlineations, alterations and erasures must be
initialed by the signer of the Proposal.
8.2 The “Bid Form” provided by the District provides a space at the bottom of the first page
for Contractors to add or deduct from their Base Bid at any time up to the official
submittal date and time. This space is identified as “Voluntary Deduct/ Add to the Base
Bid.” The deduct/add amount cannot exceed 25% of the Base Bid; if it does, the Bidder
will be disqualified from the procurement.
9. Equitable Distribution (Maximum 15 points):
9.1 In an effort to consider the equitable distribution of work, the Selection Process Facilitator
shall evaluate data showing dollar amounts of contracts and projects awarded by DCSD to
the submitting firm(s). The dollar amount of projects awarded will reflect the estimated
construction value listed on the RFP awarded to each firm. The projects taken into account
in the calculation will be those awarded by DCSD within two years from this RFP bid
opening. For those projects already under contract, the awarded amount will be replaced
by the GMP and/or Bid amount(s) contracted, not including change orders. For projects
recommended but not yet awarded, the contract value will reflect the estimated fee based
on the budget listed within the RFP for which the firm was selected. In the case of submittals
received by joint ventures, the projects awarded to each of the firms comprising the joint
venture will be included in the calculation of the projects awarded by DCSD. Furthermore,
this calculation will include all projects awarded to the submitting firm, either as a joint
venture or as a separate entity, whereby the submitting firm(s) was one of the entities
included in the award and/or contract.
9.2 The chart below will be used to award a maximum of 15 points based on dollar amount of
projects currently under contract, as well as those awarded by DCSD, but not yet under
contract and those recommended but not yet awarded. This single score will be allocated
to each firm by the Selection Process Facilitator and added to the cumulative score the
committee members.
Contract Value Awarded/ Recommended by DCSD Point Value
0 to $5,000,000 15 points
$5,000,001 to $10,000,000 13 points
$10,000,001 to $20,000,000 11 points
$20,000,001 to $30,000,000 9 points
$30,000,001 to $50,000,000 7 points
Greater than $50,000,000 0 points
THE INFORMATION FOR THE FOLLOWING TWO SECTIONS IS NOT TO BE INCLUDED WITH THE TECHNICAL
PROPOSAL.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 23 of 57
C. INTERVIEWS AND PRESENTATION
After evaluation of the Proposals received in response to the RFP, DeKalb County School District may
interview two or more proposers deemed fully qualified, responsive, responsible and suitable on the basis of
initial responses, and with professional competence to provide the required services.
At the time of its scheduled interview, each short-listed firm shall provide additional information about is firm
and operations as may be required by DCSD. This additional information shall include, but is not limited to,
the following:
1. Overall Approach, Methodology and Knowledge of the Site (35 points)
1.1. The firm shall provide information regarding its knowledge of working on active school
campuses, local codes and ordinances as an indication of its ability to deliver quality
workmanship in an effective and timely manner.
1.2. The firm shall demonstrate verbally and its plan for performing the services outlined in the
RFP, documenting the services to be provided and showing the interrelationship of all
parties.
2. Project Team (10 points)
2.1. The firm shall express the general and specific project related experience and capability
of in-house staff and sub-consultants and their functions as it relates to the project.
2.2. The firm shall develop an organization chart as it relates to the Project indicating key
personnel and their relationship. It shall be understood that it is the intent of the
District to insist that the staff presented at the time of the interview as those key
personnel indicated as the project team in the RFP actually executes the Project.
3. Project Scheduling (25 points)
As part of the project approach, the firm shall propose a schedule for effectively managing and
executing the work in the optimum time. Provide a schedule and describe any major milestones for
achieving the schedule and any other recommendations that may directly impact the schedule.
4. Cost Control/Value Engineering (25 points)
4.1. Describe how you develop cost estimates, and how they are updated, providing specific
examples of successful recommendations implemented and cost containment strategies
utilized to maintain project budgets without sacrificing quality.
4.2. The firm shall provide a comparison of any representative current projects demonstrating
their ability to hold to original budgets.
4.3. The firm shall provide suggestions for potential savings to the project that will maintain the
design intent and still maintain exceptional quality.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 24 of 57
5. References (5 points)
The GC must demonstrate a positive relationship with prior clients on similar projects.
5.1. The GC shall submit written recommendations from previous owners and discuss their
strategy to provide a positive working relationship with DCSD. This strategy must include
actual examples of how the GC has demonstrated their cooperation with other Owners.
DCSD reserves the option of contacting any of the references provided to confirm
information provided.
5.2. If applicable, DCSD staff will provide input on a firm’s past work performance, this
information includes but is not limited to the number of warranty requests and
responsiveness, contract and process compliance, and information from the DCSD
contractor evaluation process if available.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 25 of 57
VI.
QUALIFICATIONS FOR SELECTION AND THE SELECTION PROCESS
A. QUALIFICATIONS FOR SELECTION OF GENERAL CONTRACTOR
The evaluation of the Proposals will be based upon consideration of the demonstrated qualifications and
capabilities of the GC based on the identified evaluation factors and their relative weight, which will result in
an award that is in the best interest of the DeKalb County Board of Education.
B. SELECTION PROCESS
A Selection Committee will perform Proposal evaluations and, following completion of the evaluations and
subject to the Owner’s right to reject any or all Proposals, the responsible and responsive GC whose Proposal
is determined to be the most advantageous to the Owner will be selected to perform the GC Services for
Security Vestibules at Kelley Lake ES, Lithonia MS and Tucker High School. The evaluation factors that will
be employed, and their relative importance, are identified at Part IV, Section 14, above.
Offerors may be afforded an opportunity for discussion, negotiation and revision of Proposals for the purpose
of obtaining best and final offers. In the event the Owner deems it necessary or appropriate, responsible
Offerors found by the Owner to have submitted Proposals reasonably susceptible of being selected for award
shall be given an opportunity to participate in such discussions, negotiations and revisions.
The Owner reserves the right to reject any or all Proposals, before or after opening, for any reason whatsoever
including, but not limited to, any failure of any Proposal to be accompanied by a proper Bid Bond or by other
data required by the Proposal Documents, any incompleteness or irregularity of any Proposal received, any
evidence of collusion with the intent to defraud or other illegal practices on the part of the GC, failure to comply
with the requirements of the Proposal Documents, or exceeding the funds available. The Owner also reserves
the right to waive any technicalities or informalities, and to award the Contract in the best interests of the
Owner.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 26 of 57
VII.
PROTEST PROCESS
This section describes the mandatory administrative procedure whereby Offerors submitting sealed competitive
bids/proposals (hereinafter referred to as “bidders”) to DCSD directly related to design and construction, for proposals
worth $100,000 or more may challenge the solicitation process, and whereby bidders/Offerors on sealed competitive
bids directly related to DeKalb County School District Facilities for proposals worth $100,000 or more, may challenge contract
awards.
1. Protests. A bidder may file a written protest challenging DCSD’s compliance with applicable procurement
procedures subject to the bidder’s compliance with the provisions outlined below. Any such written protest
will be resolved in accordance with these provisions.
2. Types of Challenges. Any bidder interested in and capable of responding to a competitive solicitation
may file a protest with respect to the competitive solicitation process including, but not limited to, a
challenge to specifications or any events or facts arising during the solicitation process. Any bidder
submitting a timely bid/proposal in response to a competitive solicitation may file a protest with respect to
DCSD’s intended or actual contract award including, but not limited to, events or facts arising during the
evaluation and/or negotiation process.
3. Form of protest. At a minimum, the written protest must include the following:
a. the name and address of the protestor;
b. appropriate identification of the solicitation;
c. a statement of reasons for the protest;
d. supporting exhibits, evidence, or documents to substantiate any claims unless not available
within the filing time (in which case the Offeror must proceed to file the protest during the
filing period identified below but state the expected availability of the material); and
e. the desired remedy.
DCSD, at its discretion, may deem issues not raised in the initial protest as waived with
prejudice by the protesting Offeror.
4. Filing Protests. A protest is considered to be properly filed when it is in writing, signed by a company
officer authorized to sign contracts on behalf of the Offeror, and is received by the Procurement
Department. The protest may be sent by any of the following means:
MAIL: Attention: Mr. Erick Hofstetter
Chief Operating Officer
DeKalb County School District
Sam A. Moss Service Center
1780 Montreal Road
Tucker, Georgia 30084
EMAIL: erick_hofstetter@dekalbschoolsga.org
The Offeror must observe the following deadlines when filing a protest:
Type of Protest Protest Filing Deadline
Challenge to Competitive Solicitation Two (2) business days prior to the closing date
Process and time of the solicitation as identified on the
Invitation to Bid.
Challenge to an Intended or Actual In the event DCSD posts a Notice of Intent to
Contract Award Award (“NOIA”), the protest must be filed within
ten (10) calendar days of the date the NOIA is
posted.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 27 of 57
In the event DCSD does not post a NOIA, the
protest must be filed within ten (10) calendar
days of the date the Notice of Award (“NOA”) is
posted.
If a bidder fails to file a protest by the applicable deadline, such failure shall be deemed as a waiver
with prejudice of any grounds the bidder may have for protest.
5. Stay of procurement during protest review. When a protest challenging the competitive solicitation process
has been timely filed at least two (2) business days prior to the closing date and time, the solicitation shall
not close until a final decision resolving the protest has been issued, unless the facilities management
department makes a written determination that the closing of the solicitation without delay is necessary to
protect the interests of DCSD.
When a protest challenging an intended contract award has been timely filed, DCSD shall not proceed to
actual contract award unless the Design and Construction Department makes a written determination that the
issuance of a contract or performance of the contract without delay is necessary to protect the interests of
DCSD. If it is determined that it is necessary to proceed with contract performance without delay, the
bidder/Offeror with this contingent contract may proceed with performance and receive payment for work
performed in strict accordance with the terms of the contract. The provisions of this paragraph are not
applicable to a protest pertaining to events or facts arising during the solicitation process.
6. Protest Resolution. The Chief Operating Officer shall review and issue a written decision on the protest
within seven (7) business days. This decision shall be deemed final. Available remedies for sustained
protests are as follows:
▪ If a protest is sustained prior to the closing date and time of the solicitation, available remedies may include,
but are not limited to, the following: modification of the solicitation document including, but not limited to,
specifications and terms and conditions; extension of the solicitation closing date and time (as appropriate);
and cancellation of the solicitation.
▪ If a protest of the intended/actual contract award is sustained, available remedies may include but are not
limited to, the following: revision or cancellation of the NOIA/NOA, re-evaluation and re-award, or re-
solicitation with appropriate changes to the new solicitation.
Costs. In no event shall a bidder be entitled to recover any costs incurred in connection with the solicitation
or protest process, including, but not limited to, the costs of preparing a bid/proposal, the costs of participating
in the protest process, or any attorney fees.
(END OF RFP – SEE APPENDICES AND ATTACHMENTS)
Appendices Included in Separate Package
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 28 of 57
ATTACHMENT A: GENERAL CONTRACTOR CHECKLIST AND CERTIFICATION
The undersigned, hereby acknowledges having received Request for Proposal (RFP) No. 25-752-002 for GC
Services for Security Vestibule (Kelley Lake Elementary School, Lithonia Middle School and Tucker High
School) containing a full set of documents:
Owner’s Project Specific Information
Appendix A Owner’s Preliminary Program Narrative (3 pages)
Appendix B Special Conditions (5 pages)
Appendix C Master Project Schedule (1 page)
Appendix D DeKalb County School District 2024-2025 and 2025-2026 Calendar (2 pages)
Appendix E Fixed Price Construction Contract (44 pages)
Appendix F Subcontractor Affidavit of Non-collusion (1 page)
Appendix G Performance Bond (3 pages)
Appendix H Payment Bond (4 pages)
Appendix I Affidavit for Payment (2 pages)
IMPORTANT NOTICE: The omission of any of the required items listed below shall cause the bid
submission to be declared non-responsive and to be rejected.
Check Box to
Include with Confirm
Owner’s Standard Forms: Proposal Inclusion
Attachment A Contractor’s RFP Checklist (2 pages) YES
Attachment B1 Corporate Certificate (1 page) B1 or B2 or
Attachment B2 Partnership Certificate (1 page) B3 as
Attachment B3 Entity Certificate (1 page) applicable
Attachment C1 Subcontractor Listing Kelley Lake ES (1 page) YES
Attachment C2 Subcontractor Listing Lithonia MS (1 page) YES
Attachment C3 Subcontractor Listing Tucker HS (1 page) YES
Attachment D Offeror’s and Individuals’ Affidavit of Non-collusion (2 pages) YES
Attachment E Conflict of Interest Disclosure Form (2 pages) YES
Attachment F Form of Consent to Release Information (1 page) YES
Attachment G Vendor References Form (1 page) YES
Attachment H Bid Bond (1 page) YES
Attachment I1 Fixed Price for Construction Proposal Kelley Lake ES (4 pages) YES
Attachment I2 Fixed Price for Construction Proposal Lithonia MS (4 pages) YES
Attachment I3 Fixed Price for Construction Proposal Tucker HS (4 pages) YES
Attachment J Immigration and Security Certification (2 Pages) YES
Attachment K No Submittal Response Form (1 page) N/A
Check Box to
Include with Confirm
Other Requirements: Proposal Inclusion
Sample Certificate of Insurance, per General Conditions Item F. YES
Copy of Business and GC License, per General Conditions Item N. YES
Acknowledgement of ALL addenda (if any) below. YES
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 29 of 57
Indicate Addenda(s) Nos. _____________________________ received (none unless indicated here). The General
Contractor is responsible for reading and understanding all sections of this RFP and affirms that the General Contractor
shall be bound by all of the terms and conditions contained in this RFP.
Further, the undersigned, being duly sworn, states on oath that no disclosures of ownership have been withheld from
the Board, that the information provided herein is current, and General Contractor and its officers and employees have
not entered into any agreement with any other General Contractor or prospective General Contractor or with any other
person, firm or corporation relating to any prices or other terms named in this RFP or any other RFP, nor has it entered
into any agreement or arrangement under which a person, firm or corporation is to refrain from responding to this RFP.
Name of General Contractor:
Signature: Printed Name:
Title: Date:
Sworn to and subscribed before me this ___ day of _______________, 2_____.
Notary Public: My commission expires: __/__/__.
(SEAL)
THE DEKALB COUNTY SCHOOL DISTRICT RESERVES THE RIGHT TO REJECT ANY AND ALL PROPOSALS
AND TO WAIVE INFORMALITIES.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 30 of 57
ATTACHMENT B1: CORPORATE CERTIFICATE
(Proposals)
STATE OF _______________________
COUNTY OF _____________________
I, ________________________________, certify that I am the Secretary of the
corporation named as offeror in the foregoing proposal; that
_____________________________________ who signed said proposal on behalf of the offeror
was then _______________________ of said corporation; that said proposal was duly signed for
and in behalf of said corporation by authority of its Board of Directors, and is within the scope of
its corporate powers; and that said corporation is organized under the laws of the State of
____________________.
_____________________________________
[signature]
_____________________________________
[typed name]
Subscribed and sworn to
before me this ___ day of
_______________, 2_____.
(SEAL)
_____________________
Notary Public
My Commission Expires:
___/___/___
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 31 of 57
ATTACHMENT B2: PARTNERSHIP CERTIFICATE
Proposals
STATE OF __________________________
COUNTY OF ________________________
On this ____ day of ______________, 20______, personally appeared
_____________________________, who executed the above proposal, and being first duly
sworn, deposes and says that he or she is a general partner in the firm of
_____________________________ and that said firm consists of himself or herself and
____________________________________________ and that he or she executed the
foregoing proposal on behalf of said firm for the uses and purposes stated therein, and that no
one except the above named members of the firm have any financial interest whatsoever in said
proposed contract.
____________________________________
[Affiant’s Signature]
_________________________________ __________________________________
Partner Partner
_________________________________ __________________________________
Partner Partner
Subscribed and sworn to
before me this ___ day of
_______________, 2____.
(seal)
_______________________
Notary Public
My Commission Expires:
___/___/___
NOTE: If only one partner signs, a Power of Attorney executed by all other partners authorizing him or her
to act in the name of the partnership must be attached; otherwise, all partners must sign.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 32 of 57
ATTACHMENT B3: ENTITY CERTIFICATE
Proposals
STATE OF _______________________
COUNTY OF _____________________
I, ________________________________, certify that I am the Secretary of the entity
named as offeror in the foregoing proposal; that _____________________________________
who signed said proposal in behalf of the offeror was then _______________________ of said
entity; that said proposal was duly signed for and on behalf of said entity by due authority, and is
within the scope of its legal powers; and that said entity is a ________________________
organized under the laws of the State of ____________________.
_____________________________________
[signature]
_____________________________________
[typed name]
Subscribed and sworn to
before me this ___ day of
_______________, 2____.
(SEAL)
_____________________
Notary Public
My Commission Expires:
___/___/___
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 33 of 57
ATTACHMENT C1: SUBCONTRACTOR LISTING
(Proposals)
TO: DEKALB COUNTY BOARD OF EDUCATION RFP No. 25-752-002
hereinafter called “Owner” Project No. N/A
Pursuant to proposal requirements for the Projects known as GC Services Security Vestibule
Kelley Lake Elementary School the undersigned proposes to use the following subcontractors
for principal portions of the Project:
SUBCONTRACTOR NAME ADDRESS
PORTION OF THE WORK CONTACT PERSON TELEPHONE NUMBER
Use Additional Sheets If Necessary
Provide Signature Identical To That OFFEROR: ___________________________________
Shown On The Proposal Form [typed proper name of Offeror]
By: ______________________________________
[signature]
______________________________________
[name and title]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 34 of 57
ATTACHMENT C2: SUBCONTRACTOR LISTING
(Proposals)
TO: DEKALB COUNTY BOARD OF EDUCATION RFP No. 25-752-002
hereinafter called “Owner” Project No. N/A
Pursuant to proposal requirements for the Projects known as GC Services Security Vestibule
Lithonia Middle School the undersigned proposes to use the following subcontractors for
principal portions of the Project:
SUBCONTRACTOR NAME ADDRESS
PORTION OF THE WORK CONTACT PERSON TELEPHONE NUMBER
Use Additional Sheets If Necessary
Provide Signature Identical To That OFFEROR: ___________________________________
Shown On The Proposal Form [typed proper name of Offeror]
By: ______________________________________
[signature]
______________________________________
name and title]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 35 of 57
ATTACHMENT C3: SUBCONTRACTOR LISTING
(Proposals)
TO: DEKALB COUNTY BOARD OF EDUCATION RFP No. 25-752-002
hereinafter called “Owner” Project No. N/A
Pursuant to proposal requirements for the Projects known as GC Services Security Vestibule
Tucker High School the undersigned proposes to use the following subcontractors for principal
portions of the Project:
SUBCONTRACTOR NAME ADDRESS
PORTION OF THE WORK CONTACT PERSON TELEPHONE NUMBER
Use Additional Sheets If Necessary
Provide Signature Identical To That OFFEROR: ___________________________________
Shown On The Proposal Form [typed proper name of Offeror]
By: ______________________________________
[signature]
______________________________________
[name and title]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 36 of 57
ATTACHMENT D: OFFEROR’S and INDIVIDUALS’ AFFIDAVIT OF NON-COLLUSION
(This affidavit to be executed in accordance with O.C.G.A. § 36-91-21(e))
STATE OF ______________________
COUNTY OF ____________________
COMES NOW,
_________________________________________________________(“Offeror”),
[name of Offeror]
appearing by and through __________________________________ , it’s _________________________
[insert name of individual with [title]
authority to bind Offeror]
(averring both individually and in his or her representative capacity on behalf of Offeror) (the “Individual And
Representative Affiant”), and
_____________________________________________________________
[in these blanks insert the names of all those required to give the oath
under O.C.G.A. § 36-91-21(e)]
____________________________________________________________________________________
____________________________________________________________________________________
____________________________________________________________________________________
____________________________________________________________________________________
____________________________________________________________________________________
____________________________________________________________________________________
____________________________________________________________________________________
(collectively, the “Individual Affiants”), and each of the Individual And Representative Affiant and the
Individual Affiants, after first being duly sworn, deposes and says that:
1. He, she or it, as applicable, has not directly or indirectly violated subsection (d) of the Official
Code of Georgia Annotated Section 36-91-21, which subsection provides as follows:
(d) Whenever a public works construction contract for any governmental entity subject
to the requirements of this chapter is to be let out by competitive sealed bid or proposal, no person,
by himself or herself or otherwise, shall prevent or attempt to prevent competition in such bidding
or proposals by any means whatever. No person who desires to procure such work for himself or
herself or for another shall prevent or endeavor to prevent anyone from making a bid or proposal
therefor by any means whatever, nor shall such person so desiring the work cause or induce
another to withdraw a bid or proposal for the work.
2. If the Offeror is a partnership, then the Individual And Representative Affiant, together with the
Individual Affiants, constitute all of the partners and any officer, agent or other person who may have
represented or acted for them in bidding or proposing for or procuring the contract for the DeKalb County
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 37 of 57
Board of Education GC Services for Security Vestibule (Kelley Lake Elementary School, Lithonia
Middle School and Tucker High School) (the “Project”).
3. If the Offeror is a corporation or other entity, then the Individual And Representative Affiant,
together with the Individual Affiants, constitute all officers, agents, or other persons who may have acted
for or represented the corporation or other entity in bidding for or procuring the contract for the Project.
Further, the Individual And Representative Affiant and the Individual Affiants sayeth not.
This _______ day of _______________, 2____
_____________________________________
[insert name of Offeror]
and ___________________________________________
[insert name of Individual And Representative Affiant]
By: ___________________________________, both individually and on behalf of Offeror as its
[signature]
_________________________________
[insert title]
Individual Affiants’ signatures and names:
x_____________________________________ x____________________________________
Name: Name:
x_____________________________________ x____________________________________
Name: Name:
x_____________________________________ x____________________________________
Name: Name:
x_____________________________________ x____________________________________
Name: Name:
x_____________________________________ x____________________________________
Name: Name:
x_____________________________________ x____________________________________
Name: Name:
Sworn to and subscribed before me this ___ day of _______________, 2____.
Notary Public: _____________________ My commission expires: __/__/__.
(SEAL)
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 38 of 57
ATTACHMENT E: CONFLICT OF INTEREST DISCLOSURE AFFIDAVIT
I HEREBY CERTIFY, UNDER OATH, that
1. I (Printed Name), ______________________________________ am the (Title)
_________________________________________________ and I am the duly authorized
representative of the firm of (Firm Name) _______________________
_____________________________________________ (the “Firm”) for purposes of this
Affidavit, whose address is (Firm Address) _________________________
________________________, and I possess the legal authority to make this Affidavit on
behalf of myself and the Firm, as follows:
2. The following employee(s), officer(s) or agent(s) of the Firm (collectively, “Firm
Representative”) is/are related, by blood or marriage, to an employee, agent or Board
Member of the DeKalb County Board of Education (collectively, “Owner
Representative”), as indicated below:
Firm Representative Owner Representative Relation
________________ __________________ __________________
________________ __________________ __________________
________________ __________________ __________________
________________ __________________ __________________
________________ __________________ __________________
3. Except as listed below under “EXCEPTIONS”, neither the Firm nor any Firm
Representative have any conflicts of interest, whether real or potential, due to kinship,
ownership, other clients, other contracts, interests, or otherwise concerning the DeKalb
County Board of Education, the Project or any Owner Representative:
EXCEPTIONS (fully disclose and completely explain)
[Continued on Next Page]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 39 of 57
4. This disclosure is made without prior understanding, agreement, or connection with any
corporation, firm or person submitting a bid, proposal or qualification statement for the same
contract or project, and is in all respects without collusion or fraud.
Wherefore, the foregoing disclosure is fully complete and true, and may be relied upon by the
DeKalb County Board of Education:
Signature: ____________________________________________
Printed Name: ____________________________________________
Firm Name: ____________________________________________
Date: ____________________________________________
Sworn to and described before me this ________ day of _______________________
Personally known: ____________________________________________
OR Produced Identification: ____________________________________________
Type of Identification: ____________________________________________
Notary Public – State of ____________________________________________
My Commission Expires ____________________________________________
Affix Notary Seal Here:
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 40 of 57
ATTACHMENT F: CONSENT TO RELEASE INFORMATION
The undersigned, having submitted a competitive sealed Proposal to the DeKalb
County Board of Education in respect of a local government entity public works
construction project (or being a partner in a joint venture that has submitted such
proposal), hereby authorizes any person or entity having in its possession, custody or
control any information regarding the undersigned to fully disclose and make available
such information to the DeKalb County Board of Education, its agents, attorneys and
other representatives.
This ___ day of _______________, 2_____.
_____________________________________________________
[Printed name of person or entity consenting to release of information]
By: ___________________________________
Printed name: ___________________________
Printed Title: ____________________________
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 41 of 57
ATTACHMENT G: VENDOR REFERENCE FORM
VENDOR REFERENCES FOR: ____________________________________
Insert Company Name
References must be completed by ALL Vendors. It is the vendor’s responsibility to provide COMPLETE and
ACCURATE reference information on the form below; completing ALL fields. Failure to do so can result in
DCSD being unable to verify vendor’s past work, which may affect DCSD’s determination that the vendor is
responsive and responsible. DCSD reserves the right to consider past experience with vendor.
1. __________________________________________________________________________________
Company
__________________________________________________________________________________
Address, City, State, Zip Code
___________________________________ _______________________________________
Telephone Number Fax Number
___________________________________ _______________________________________
Name of Contact Person E-Mail Address
2. __________________________________________________________________________________
Company
__________________________________________________________________________________
Address, City, State, Zip Code
___________________________________ _______________________________________
Telephone Number Fax Number
___________________________________ _______________________________________
Name of Contact Person E-Mail Address
3. __________________________________________________________________________________
Company
__________________________________________________________________________________
Address, City, State, Zip Code
___________________________________ _______________________________________
Telephone Number Fax Number
___________________________________ _______________________________________
Name of Contact Person E-Mail Address
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 42 of 57
ATTACHMENT H: BID BOND
KNOW ALL PERSONS BY THESE PRESENTS, that we, _______________________,
[insert proper name of Surety]
a corporation duly organized and existing under the laws of the State of ________________,
as surety (“Surety”), and _______________________________________________________
[Insert proper name and address of Bidder]
as principal (“Bidder”), enter into, execute this bond (“Bid Bond”), and firmly bind ourselves,
our heirs, administrators, executors and successors, jointly and severally, in favor of the
DeKalb County Board of Education, as obligee (“Owner”), in the penal sum of:
_____________________________________________ dollars ($____________________),
[Insert penal sum, written in words and in numerals, which shall equal 5% of the Base Bid]
as of the ____ day of _________________ 20___.
WHEREAS, the Bidder has submitted a bid for construction of the DCSD Project, GC Services
for Security Vestibule (Kelley Lake Elementary School, Lithonia Middle School and Tucker
High School) (RFP No. 25-752-002) Project in DeKalb County, Georgia; and
WHEREAS, the Owner has required the Bidder to furnish this Bid Bond containing the
terms and conditions set forth herein as a condition to submission of the bid;
NOW THEREFORE, the Surety and the Bidder, for themselves, their heirs, administrators,
executors and successors, both joint and severally, agree that if the Owner accepts the bid of the
Bidder and within ninety (90) days of the bid opening delivers to the Bidder a Notice of Award,
and the Bidder, within ten (10) calendar days after receipt of such Notice of Award, has not
executed a contract with the Owner in accordance with the terms of such bid and furnished such
bonds as are specified in the bidding documents with good and sufficient surety for the faithful
performance of such contract and for the prompt payment of labor and materials furnished in the
prosecution thereof, then the Surety and the Bidder shall pay to the Owner the full penal sum
hereof as liquidated damages and not as a penalty.
SIGNED AND SEALED this ____ day of __________________, 2_____.
BIDDER SURETY
_____________________________[SEAL] ____________________________[SEAL]
[Typed Name] [Typed Name]
BY:_______________________________ BY:_______________________________
[Signature] [Signature]
__________________________________ __________________________________
[Printed Name, Title and Address] [Printed Name, Title and Address]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 43 of 57
ATTACHMENT I1: General Contractor Fixed Price Proposal
BID FORM
DeKalb County Board of Education
Sam A. Moss Service Center
1780 Montreal Road
Tucker, Georgia 30084
The “Bid Form” provided by the District provides a space in section B below for
Contractors to add or deduct from their Base Bid at any time up to the official submittal
date and time. This space is identified as “Voluntary Deduct/ Add to the Base Bid.” The
deduct/add amount cannot exceed 25% of the Base Bid; if it does, the Bidder will be
disqualified from the procurement.
No changes to the “Bid Form” are permitted. Any changes to the “Bid Form” can result in
the bidder being disqualified from the procurement.
In compliance with the Request for Sealed Proposals, the undersigned Contractor,
____________________________________________,
[legal name of Contractor]
____________________________________________
____________________________________________,
[address of Contractor]
____________________________________________,
[telephone number of Contractor]
having carefully examined the proposed Standard Form of Fixed Price Construction
Contract (the “Agreement” or the “Contract”) and the Owner’s other Proposal Documents
included or referenced in the Request for Proposals, any Addenda thereto, for GC
Services for Security Vestibule Kelley Lake Elementary School, proposes and agrees,
if this proposal is accepted, to enter into the Agreement with the Owner and to perform
the Work including all services, supervision, labor, coordination, equipment and material
in conformance with the Contract Documents, in the time and for the Contract Price set
forth below, and submits the following proposed Fixed Price, schedule and other matters
set forth below:
a. The proposed Fixed Price amount to insert in as the Contract Price in Section 6.1 of the
Agreement:
1. General Conditions $
2. Site Work $
3. Concrete $
4. Masonry $
5. Metals $
6. Carpentry $
7. Thermal and Moisture Protection $
8. Doors and Windows $
9. Finishes and Accessories $
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 44 of 57
10. Specialties $
11. Equipment $
12. Furnishings $
13. Special Construction $
14. Conveying Systems $
15. Mechanical $
16. Electrical $
Total Base Bid $
_________________________________________ dollars
Total Base Bid written in words
b. Voluntary Deduct/Add to Base Bid
_________________________________________________________________dollars
(written in words)
($___________________________), shall be added / deducted (circle which one) from
the Base Bid.
c. Alternates to your Base Bid
The undersigned Contractor further agrees that if any of the following Alternates as
described in the RFP Documents are accepted, the following amounts shall be deducted
from or added to the Fixed Price as indicated:
None.
d. Unit Prices and Allowances: The undersigned Contractor further agrees to the
following unit prices. The unit prices are amounts to be used for work that will be added
to or deleted from the Contract by Change Order in the event such additional work may
be required. The quantities shown (in parenthesis) on the following schedule shall be in
the Base Bid as an Allowance at the rates that the Contractor proposes.
Unit prices are complete for labor, equipment, material, the hauling in of needed material
and the hauling off and disposal of excess and unsuitable material, installation, applicable
taxes, overhead and profit and all other incidental costs. Units will be measured in place.
OWNER reserves the right to accept or reject these unit prices or require the Work to be
performed on a time and material basis with complete daily breakdowns and logs
submitted.
None.
The Contractor understands that the Owner reserves the right to reject any or all
Proposals, and to waive any technicalities and informalities.
The Contractor agrees that this Proposal may not be withdrawn for a period of ninety (90)
calendar days after the date and time fixed for receiving said Proposals.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 45 of 57
The person signing this bid form must be legally authorized to bind the company.
Respectfully submitted,
______________________________________
[typed name of Contractor]
By: __________________________________[seal]
[signature]
__________________________________________
[typed name and title]
__________________________________________
[address of Contractor]
(_____)____________________________________
[business telephone number]
__________________________________________
[date of execution]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 46 of 57
[If the Contractor is a joint venture, utilize this page of this proposal form for signatures.]
By submission of this Proposal, the Contractor certifies that this Proposal has been
derived independently, without consultation, communication or agreement as to any matter
relating to this Proposal with any other Contractor or with any competitor. The Contractor hereby
certifies that this Proposal is made without prior understanding, agreement or connection with any
corporation, firm or person submitting a proposal for the same Project and is in all respects fair
and without collusion or fraud. If successful in its Proposal, the Contractor will timely submit to
the Owner the Offeror’s and Individuals’ Affidavit of Non-collusion and the Subcontractor’s
Affidavit of Non-collusion in the form, manner and number, required by the Request for Proposals
and applicable laws. The Contractor agrees to abide by all conditions of the Request for Proposal.
Respectfully submitted ________________________________________________________,
[typed name of Joint Venture]
By: _________________________________
[typed name of Joint Venture partner]
By: __________________________________[seal]
[signature]
__________________________________________
[typed name and title]
__________________________________________
[address of Joint Venture partner]
(_____)____________________________________
[business telephone number]
__________________________________________
[date of execution]
By: __________________________________
[typed name of Joint Venture partner]
By: __________________________________[seal]
[signature]
__________________________________________
[typed name and title]
__________________________________________
[address of Joint Venture partner]
(_____)____________________________________
[business telephone number]
__________________________________________
[date of execution]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 47 of 57
ATTACHMENT I2: General Contractor Fixed Price Proposal
BID FORM
DeKalb County Board of Education
Sam A. Moss Service Center
1780 Montreal Road
Tucker, Georgia 30084
The “Bid Form” provided by the District provides a space in section B below for
Contractors to add or deduct from their Base Bid at any time up to the official submittal
date and time. This space is identified as “Voluntary Deduct/ Add to the Base Bid.” The
deduct/add amount cannot exceed 25% of the Base Bid; if it does, the Bidder will be
disqualified from the procurement.
No changes to the “Bid Form” are permitted. Any changes to the “Bid Form” can result in
the bidder being disqualified from the procurement.
In compliance with the Request for Sealed Proposals, the undersigned Contractor,
____________________________________________,
[legal name of Contractor]
____________________________________________
____________________________________________,
[address of Contractor]
____________________________________________,
[telephone number of Contractor]
having carefully examined the proposed Standard Form of Fixed Price Construction
Contract (the “Agreement” or the “Contract”) and the Owner’s other Proposal Documents
included or referenced in the Request for Proposals, any Addenda thereto, for GC
Services for Security Vestibule Lithonia Middle School, proposes and agrees, if this
proposal is accepted, to enter into the Agreement with the Owner and to perform the Work
including all services, supervision, labor, coordination, equipment and material in
conformance with the Contract Documents, in the time and for the Contract Price set forth
below, and submits the following proposed Fixed Price, schedule and other matters set
forth below:
a. The proposed Fixed Price amount to insert in as the Contract Price in Section 6.1 of the
Agreement:
1.General Conditions $
2.Site Work $
3.Concrete $
4.Masonry $
5.Metals $
6.Carpentry $
7.Thermal and Moisture Protection $
8.Doors and Windows $
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 48 of 57
9. Finishes and Accessories $
10. Specialties $
11. Equipment $
12. Furnishings $
13. Special Construction $
14. Conveying Systems $
15. Mechanical $
16. Electrical $
Total Base Bid $
_________________________________________ dollars
Total Base Bid written in words
b. Voluntary Deduct/Add to Base Bid
_________________________________________________________________dollars
(written in words)
($___________________________), shall be added / deducted (circle which one) from
the Base Bid.
C Alternates to your Base Bid
The undersigned Contractor further agrees that if any of the following Alternates as
described in the RFP Documents are accepted, the following amounts shall be deducted
from or added to the Fixed Price as indicated:
None.
d. Unit Prices and Allowances: The undersigned Contractor further agrees to the
following unit prices. The unit prices are amounts to be used for work that will be added
to or deleted from the Contract by Change Order in the event such additional work may
be required. The quantities shown (in parenthesis) on the following schedule shall be in
the Base Bid as an Allowance at the rates that the Contractor proposes.
Unit prices are complete for labor, equipment, material, the hauling in of needed material
and the hauling off and disposal of excess and unsuitable material, installation, applicable
taxes, overhead and profit and all other incidental costs. Units will be measured in place.
OWNER reserves the right to accept or reject these unit prices or require the Work to be
performed on a time and material basis with complete daily breakdowns and logs
submitted.
None.
The Contractor understands that the Owner reserves the right to reject any or all
Proposals, and to waive any technicalities and informalities.
The Contractor agrees that this Proposal may not be withdrawn for a period of ninety (90)
calendar days after the date and time fixed for receiving said Proposals.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 49 of 57
The person signing this bid form must be legally authorized to bind the company.
Respectfully submitted,
______________________________________
[typed name of Contractor]
By: __________________________________[seal]
[signature]
__________________________________________
[typed name and title]
__________________________________________
[address of Contractor]
(_____)____________________________________
[business telephone number]
__________________________________________
[date of execution]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 50 of 57
[If the Contractor is a joint venture, utilize this page of this proposal form for signatures.]
By submission of this Proposal, the Contractor certifies that this Proposal has been
derived independently, without consultation, communication or agreement as to any matter
relating to this Proposal with any other Contractor or with any competitor. The Contractor hereby
certifies that this Proposal is made without prior understanding, agreement or connection with any
corporation, firm or person submitting a proposal for the same Project and is in all respects fair
and without collusion or fraud. If successful in its Proposal, the Contractor will timely submit to
the Owner the Offeror’s and Individuals’ Affidavit of Non-collusion and the Subcontractor’s
Affidavit of Non-collusion in the form, manner and number, required by the Request for Proposals
and applicable laws. The Contractor agrees to abide by all conditions of the Request for Proposal.
Respectfully submitted ________________________________________________________,
[typed name of Joint Venture]
By: _________________________________
[typed name of Joint Venture partner]
By: __________________________________[seal]
[signature]
__________________________________________
[typed name and title]
__________________________________________
[address of Joint Venture partner]
(_____)____________________________________
[business telephone number]
__________________________________________
[date of execution]
By: __________________________________
[typed name of Joint Venture partner]
By: __________________________________[seal]
[signature]
__________________________________________
[typed name and title]
__________________________________________
[address of Joint Venture partner]
(_____)____________________________________
[business telephone number]
__________________________________________
[date of execution]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 51 of 57
ATTACHMENT I3: General Contractor Fixed Price Proposal
BID FORM
DeKalb County Board of Education
Sam A. Moss Service Center
1780 Montreal Road
Tucker, Georgia 30084
The “Bid Form” provided by the District provides a space in section B below for
Contractors to add or deduct from their Base Bid at any time up to the official submittal
date and time. This space is identified as “Voluntary Deduct/ Add to the Base Bid.” The
deduct/add amount cannot exceed 25% of the Base Bid; if it does, the Bidder will be
disqualified from the procurement.
No changes to the “Bid Form” are permitted. Any changes to the “Bid Form” can result in
the bidder being disqualified from the procurement.
In compliance with the Request for Sealed Proposals, the undersigned Contractor,
____________________________________________,
[legal name of Contractor]
____________________________________________
____________________________________________,
[address of Contractor]
____________________________________________,
[telephone number of Contractor]
having carefully examined the proposed Standard Form of Fixed Price Construction
Contract (the “Agreement” or the “Contract”) and the Owner’s other Proposal Documents
included or referenced in the Request for Proposals, any Addenda thereto, for GC
Services for Security Vestibule Tucker High School, proposes and agrees, if this
proposal is accepted, to enter into the Agreement with the Owner and to perform the Work
including all services, supervision, labor, coordination, equipment and material in
conformance with the Contract Documents, in the time and for the Contract Price set forth
below, and submits the following proposed Fixed Price, schedule and other matters set
forth below:
a. The proposed Fixed Price amount to insert in as the Contract Price in Section 6.1 of the
Agreement:
1.General Conditions $
2.Site Work $
3.Concrete $
4.Masonry $
5.Metals $
6.Carpentry $
7.Thermal and Moisture Protection $
8.Doors and Windows $
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 52 of 57
9.Finishes and Accessories
10.Specialties $
11.Equipment $
12.Furnishings $
13.Special Construction $
14.Conveying Systems $
15.Mechanical $
16.Electrical $
Total Base Bid $
_________________________________________ dollars
Total Base Bid written in words
b. Voluntary Deduct/Add to Base Bid
_________________________________________________________________dollars
(written in words)
($___________________________), shall be added / deducted (circle which one) from
the Base Bid.
C. Alternates to your Base Bid
The undersigned Contractor further agrees that if any of the following Alternates as
described in the RFP Documents are accepted, the following amounts shall be deducted
from or added to the Fixed Price as indicated:
None.
d. Unit Prices and Allowances: The undersigned Contractor further agrees to the
following unit prices. The unit prices are amounts to be used for work that will be added
to or deleted from the Contract by Change Order in the event such additional work may
be required. The quantities shown (in parenthesis) on the following schedule shall be in
the Base Bid as an Allowance at the rates that the Contractor proposes.
Unit prices are complete for labor, equipment, material, the hauling in of needed material
and the hauling off and disposal of excess and unsuitable material, installation, applicable
taxes, overhead and profit and all other incidental costs. Units will be measured in place.
OWNER reserves the right to accept or reject these unit prices or require the Work to be
performed on a time and material basis with complete daily breakdowns and logs
submitted.
None.
The Contractor understands that the Owner reserves the right to reject any or all
Proposals, and to waive any technicalities and informalities.
The Contractor agrees that this Proposal may not be withdrawn for a period of ninety (90)
calendar days after the date and time fixed for receiving said Proposals.
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 53 of 57
The person signing this bid form must be legally authorized to bind the company.
Respectfully submitted,
______________________________________
[typed name of Contractor]
By: __________________________________[seal]
[signature]
__________________________________________
[typed name and title]
__________________________________________
[address of Contractor]
(_____)____________________________________
[business telephone number]
__________________________________________
[date of execution]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 54 of 57
[If the Contractor is a joint venture, utilize this page of this proposal form for signatures.]
By submission of this Proposal, the Contractor certifies that this Proposal has been
derived independently, without consultation, communication or agreement as to any matter
relating to this Proposal with any other Contractor or with any competitor. The Contractor hereby
certifies that this Proposal is made without prior understanding, agreement or connection with any
corporation, firm or person submitting a proposal for the same Project and is in all respects fair
and without collusion or fraud. If successful in its Proposal, the Contractor will timely submit to
the Owner the Offeror’s and Individuals’ Affidavit of Non-collusion and the Subcontractor’s
Affidavit of Non-collusion in the form, manner and number, required by the Request for Proposals
and applicable laws. The Contractor agrees to abide by all conditions of the Request for Proposal.
Respectfully submitted ________________________________________________________,
[typed name of Joint Venture]
By: _________________________________
[typed name of Joint Venture partner]
By: __________________________________[seal]
[signature]
__________________________________________
[typed name and title]
__________________________________________
[address of Joint Venture partner]
(_____)____________________________________
[business telephone number]
__________________________________________
[date of execution]
By: __________________________________
[typed name of Joint Venture partner]
By: __________________________________[seal]
[signature]
__________________________________________
[typed name and title]
__________________________________________
[address of Joint Venture partner]
(_____)____________________________________
[business telephone number]
__________________________________________
[date of execution]
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 55 of 57
ATTACHMENT J: IMMIGRATION AND SECURITY CERTIFICATION
If you are providing service, performing work or delivering goods to the DeKalb County
Board of Education/DeKalb County School District including, but not limited to schools,
warehouses and central offices, the applicable Georgia Security and Immigration
Compliance documents found here must be completed, signed, notarized and submitted with
your bid/proposal. Failure to provide this document with your bid/proposal will result in the
disqualification of the bid/proposal.
1) Offeror/Bidder (the "Offeror") shall at all times comply with the Georgia Security and
Immigration Compliance Act, as amended, O.C.G.A. § 13-10-90 et. seq.
2) In order to insure compliance with the Immigration Reform and Control Act of 1986
(IRCA), D.L. 99-603 and the Georgia Security and Immigration Compliance Act, as amended by
the Illegal Immigration Reform Act of 2011, O.C.G.A. § 13-10-90 et. seq. (collectively the “Act”),
the Offeror MUST INITIAL the statement applicable to Offeror below:
(a) ________ (Initial here): Offeror declares under penalties of perjury that,
Offeror has registered at https://e-verify.uscis.gov/enroll/ to verify information of
all new employees in order to comply with the Act; is authorized to use and uses
the federal authorization program under the federal work authorization user
identification number issued on the date of authorization below; will continue to
use the authorization program throughout the contract period; Offeror further
warrants and agrees Offeror shall execute and return any and all affidavits required
by the Act and the rules and regulations issued by the Georgia Department of Labor
as set forth at Rule 300-10-1-.01 et. seq. [Offerors who initial (a) must attach
and return a signed, notarized Contractor Affidavit and Agreement with the
Contract if awarded];
or
(b) ________ (Initial here): Offeror warrants that he/she does not employ any
other persons, and he/she does not intend to hire any employees or to perform the
Contract. [Offerors who initial (b) must attach and return a signed, notarized
Affidavit of Exception with the Contract if awarded];
or
(c) _______ (Initial here) Offeror is an individual who is licensed pursuant
to Title 26 or Title 43 or by the State Bar of Georgia and is in good standing
when such contract is for services to be rendered by such individual and thus
does not have to provide an affidavit.
3) _____ (Initial here) Offeror will not employ or contract with any subcontractor in
connection with a covered contract unless the subcontractor is registered, authorized
to use, and uses the federal work authorization program; and provides Offeror with all
affidavits required by the Act and the rules and regulations issued by the Georgia
Department of Labor as set forth at Rule 300-10-1-.01 et. seq.
4) _____(Initial here) Offeror agrees that, if Offeror employs or contracts with any sub-
contractor in connection with the covered contract under the Act and DOL Rules 300-10-
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 56 of 57
1-.01, et seq that Offeror will secure from each sub-contractor at the time of the contract
the sub-contractor’s name and address, the employee-number applicable to the sub-
contractor, the date the authorization to use the federal work authorization program was
granted to sub-contractor; the subcontractor’s attestation of the subcontractor’s compliance
with the Act and Georgia Department of Labor Rule 300-10-1-.01, et seq.; and the
subcontractor’s agreement not to contract with sub-subcontractors unless the sub-
subcontractor is registered, authorized to use, and uses the federal work authorization
program; and provides subcontractor with all affidavits required by the Act and the rules
and regulations issued by the Georgia Department of Labor as set forth at Rule 300-10-1-
.01 et. seq.
5) ______ (Initial here) Offeror agrees to provide the DeKalb County School District with
all affidavits of compliance as required by O.C.G.A. § 13-10-90 et seq. and Georgia
Department of Labor Rules 300-10-1-.01, et seq within five (5) business days of receipt.
_________________________________ ______________________________
Signature Date
____________________________________ _______________________________
EEV/Basic Pilot Program Date of Authorization
User Identification Number
Firm Name: __________________________________________________________
Street/Mailing Address: ________________________________________________
City, State, Zip Code: __________________________________________________
Telephone Number: ___________________________________________________
Email Address: _______________________________________________________
SUBSCRIBED AND SWORN
BEFORE ME ON THIS THE
______ DAY OF_____________________, 20____
Notary Public
My Commission Expires:
DeKalb County School District RFP No. 25-752-002
Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
January 9, 2025 Page 57 of 57
ATTACHMENT K: NO SUBMITTAL RESPONSE FORM
RFP Number: 24-752-002
Title: GC Services for Security Vestibule (Kelley Lake ES, Lithonia MS and Tucker HS)
If your company will not be submitting a proposal in response to this Request for Proposal, please complete this form
and return prior to the RFP due date established within to:
DeKalb County Board of Education (the “Board”)
Attention: Procurement Manager
Email: angela_arlene-myrick@dekalbschoolsga.org
This information will assist Procurement Services in the preparation of future RFPs.
Company Name: ______________________________________________________________
Contact: ____________________________________________________________________
Address: ____________________________________________________________________
Telephone: _________________________________ Fax: ____________________________
Email: _______________________________________________________________________
Please check reason for a “no submittal.”
_____ Specifications ‘too tight,” geared toward one brand or manufacturer (explain below)
_____ Insufficient time to respond
_____ Specifications unclear (explain below)
_____ We do not offer this service or an equivalent
_____ Our schedule does not permit us to perform
_____ Unable to meet specifications
_____ Unable to meet bond requirements
_____ Unable to hold prices respondent throughout the term of the contract period
_____ Unable to meet insurance requirements
_____ Other________________________________________________________________
Explanation: __________________________________________________________________
____________________________________________________________________________
If submitting this form, only this form needs to be returned.
(End of RFP Document Consisting of 57 Pages)